Terms & Conditions

These Terms and Conditions ("Terms") govern your use of the services provided by THE FORT 33912 LLC ("Company," "we," "our") and your access to our website. By engaging our services or using our website, you agree to be bound by these Terms.

1. Services

THE FORT 33912 LLC provides gym equipment sales, delivery, and professional installation services for residential and commercial clients. All services are subject to availability and the specific terms outlined in written quotes or contracts provided to the client.

2. Quotes and Pricing

All quotes are valid for 30 days from the date of issue unless otherwise specified in writing. Prices are subject to change based on equipment availability, freight costs, and scope modifications. A signed agreement and deposit are required to confirm any project.

3. Payment Terms

• A deposit of 50% of the total project cost is required to initiate procurement and scheduling
• The remaining balance is due upon completion of installation and final walkthrough
• Accepted payment methods include check, ACH bank transfer, and major credit cards
• Late payments are subject to a 1.5% monthly finance charge

4. Delivery and Installation

We will make reasonable efforts to meet agreed-upon delivery and installation timelines. However, THE FORT 33912 LLC is not liable for delays caused by freight carriers, manufacturer lead times, weather events, or client-side access issues. All installations are performed by trained technicians following manufacturer specifications and applicable safety codes.

5. Site Conditions

Clients are responsible for ensuring the installation site is accessible, structurally adequate for the equipment being installed, and clear of obstructions prior to the scheduled installation date. Additional charges may apply if site conditions require non-standard installation methods or delays.

6. Warranties

All equipment carries the applicable manufacturer warranty. THE FORT 33912 LLC provides a 1-year labor warranty on all installation work performed by our technicians. Warranty claims do not cover damage caused by misuse, unauthorized modifications, or failure to follow provided maintenance guidelines.

7. Returns and Cancellations

All sales of equipment are final once procurement has been initiated. Equipment that has been delivered and assembled is not eligible for return unless defective upon delivery. Project cancellations after procurement has begun will forfeit the deposit paid. Cancellations prior to procurement may be eligible for a partial refund at the Company's discretion.

8. Limitation of Liability

THE FORT 33912 LLC's total liability to any client for any claim arising out of or related to these Terms or our services shall not exceed the total amount paid by the client for the specific project giving rise to the claim. We shall not be liable for any indirect, incidental, consequential, or punitive damages.

9. Indemnification

You agree to indemnify and hold harmless THE FORT 33912 LLC, its officers, employees, and contractors from any claims, damages, losses, or expenses arising from your misuse of equipment, failure to follow safety guidelines, or breach of these Terms.

10. Governing Law

These Terms shall be governed by and construed in accordance with the laws of the State of Florida. Any disputes arising under these Terms shall be subject to the exclusive jurisdiction of the courts located in Lee County, Florida.

11. Modifications

We reserve the right to modify these Terms at any time. Updated Terms will be posted on our website with a revised effective date. Continued use of our services constitutes acceptance of the updated Terms.

12. Contact

For questions regarding these Terms, contact us at:

THE FORT 33912 LLC
12960 Commerce Lakes Dr, Unit A13
Fort Myers, FL 33913
Phone: 239-258-1267
Email: info@thefort33912.com